Mastering Extension of Time (EOT) Clauses in Construction Projects
×

Construction’s Extension of Time (EOT) Clause – How to Maximise its Benefits

When unforeseen circumstances knock a construction schedule off kilter, a contractor may apply for an EOT. However, companies often dispute EOT clauses because they are notoriously tricky. We look at how to take the sting out of their tail.

In the construction industry, time is money.

Unforeseen challenges and unavoidable events can have significant scheduling and financial implications for all parties. If circumstances beyond the contractor’s control delay a project, ideally, the EOT clause in a construction contract should ensure the fair and practical allocation of risks.

Every construction contract is unique. Before signing, all parties must have a solid understanding of the EOT clause. If the contractor fails to meet any aspect of the clause requirements fully, this may invalidate their EOT application. The inevitable missed deadline will then constitute a breach of contract and incur financial penalties.

What is an EOT Clause?

The EOT clause in a construction contract is an essential tool that can help manage project delays and allocate the associated risks should unforeseen events occur at any point.

As the name suggests, the clause allows the company to adjust the project schedule under certain specified circumstances.

The contract should clearly state the events that will trigger an EOT entitlement. Typical examples include adverse weather conditions, unforeseen site conditions, delays caused by the client or a third party (such as the client’s consultant or nominated contractor), changes in project scope or a ‘force majeure’ event, such as war, terrorism or the outbreak of disease (COVID-19 was a prime example).

The client and/or their legal team draw up the draft contract for the contractor to review. The contract negotiation phase allows both parties to scrutinise the EOT clause and request any revisions they feel are needed.

Never underestimate the importance of the EOT clause in the negotiation phase. Don’t be under any illusions: although the clause aims to clarify and prevent disputes, it can also accelerate them.

When the chips are down, you don’t want to discover that you’ve left enough ‘wiggle room’ in the contract for the other party to hide behind. Consider whether the proposed wording of the EOT clause covers all your bases. Because once the contract is signed, you’re locked into the deal.

What’s Included in an EOT Clause?

There’s no one-size-fits-all format for the EOT clause in a construction contract. However, it usually includes some of the following features (it’s not an exhaustive list):

  • Triggers – the events or circumstances specified for EOT entitlement
  • Notice requirements – the timeframe, content and format for a valid notice of delay
  • Documentation requirements – evidence and/or documents to support the EOT claimEnsurent process – how the client will assess the contractor’s entitlement to an EOT
  • Approval process – how and when the client will approve (or reject) the EOT claim
  • Extension duration – the clause may restrict the EOT to a set number of days or a percentage of the overall project duration, depending on the nature and severity of the delay
  • Limitations and exclusions – circumstances that will restrict the contractor’s entitlement to an EOT, such as negligence
  • Concurrent delays – the process for assessing delays caused by simultaneous events or factors
  • Liquidated damage provisions – how delays covered by the EOT clause will be taken into account when calculating contractor penalties for missed deadlines
  • Dispute resolution – how any EOT disputes will be managed (negotiation, mediation or arbitration, for example).

The EOT clause in a construction contract is also likely to emphasise that the contractor must make reasonable efforts to mitigate the delay and any resulting loss (even if they aren’t at fault) and to complete the work within a reasonable timescale.

What are the Impacts of an EOT Clause?

In construction contracts, an EOT clause does what it says on the tin: it extends the time allowed to complete a specified aspect of a project. In some cases, the contractor can go beyond the agreed final delivery deadline.

Incorporating an EOT clause within a construction contract is always a good idea. This is because it provides a process to follow should an unexpected event arise. However, the consequences of implementing an EOT clause can ripple through to everyone involved in the project. For example:

  • The client may incur extra financing costs and liquidated damages
  • The contractor may have additional expenditures relating to labour, materials, equipment and overheads
  • The coordination and integration of critical activities may be disrupted, creating inefficiencies and rework in other parts of the project
  • The delay may cause scheduling and financial difficulties for subcontractors and suppliers as it cascades down the supply chain.

It’s widely acknowledged within the construction industry that EOT applications don’t always run smoothly—to put it mildly. Suppose the clause is worded ambiguously or lacks detail. In that case, the contractor’s entitlement to an EOT, the duration of the EOT, and/or the person responsible for the delay may come into dispute.

Unresolved disputes can lengthen project delays, significantly increase costs (particularly if they become litigious) and cause reputational damage.

How to Navigate the EOT Clause Successfully

Unexpected events can blow construction schedules – and budgets – out of the water.

If you’re a contractor, responding quickly and by the contract terms is essential to improve the likelihood of securing an EOT from your client. An unsuccessful application could result in a costly and protracted dispute and financial penalties for late delivery. To navigate the EOT clause successfully

  1. Make sure you fully understand the contract’s EOT clause – the terms you agree to should be clear, unambiguous and fair
  2. Introduce robust project management processes to identify, assess and address potential delays efficiently
  3. Maintain comprehensive and easily accessible project records so that if you need to apply for an EOT, you can quickly and clearly provide the required documentation and demonstrate that you’ve taken reasonable steps to mitigate delays and minimise their impact
  4. Meet all requirements stipulated in the clause – failure to tick all the boxes may invalidate your application
  5. Keep lines of communication open and be proactive – communicate delays and EOT requests to the client openly and transparently at the earliest opportunity
  6. Maintain a collaborative mindset – negotiating fairly is more likely to facilitate timely dispute resolution than adopting a combative approach.

If you’re the client, you also need to have a solid understanding of the EOT clause, its requirements and its ramifications to implement it effectively and minimise the length and impact of the delay.

For both parties, gathering and presenting the necessary EOT information promptly and in a clear and organised way will improve the chances of achieving a mutually positive outcome. Robust document management practices are a must-have.

How Can a Construction ERP System Ease the EOT Burden?

An enterprise resource planning (ERP) system combines a centralised database with a suite of interconnected modules that enable live data updates from various sources and in different formats to be integrated within the system.

With the right system in place, you can take the legwork out of EOT formalities. Here are some examples of how RedSky’s construction-specific ERP solution can help:

  • Document Management – all delays, disruptions and communications related to EOTs are meticulously documented, including all correspondence, meeting minutes, change orders and variations. They are stored securely in a digitised format on the ERP system, along with all other project documents, ready for speedy retrieval or analysis
  • Business Analytics capabilities – the system’s robust analytics and reporting capabilities make real-time information visible on customised dashboards that enable users to ‘drill down’ to specific transactions. Reports are easy to set up and can then be generated at the touch of a button to facilitate decision-making – sharing them with stakeholders can improve transparency and ensure accountability
  • Project Cost Analysis – all expense data for the construction project are tracked and stored within the ERP system, including costs for labour, materials, equipment hire, subcontractors and overheads. By comparing budgeted and actual costs, the system can identify additional expenses incurred during the extension period and generate insights into how the delay affected the profitability of the project
  • Change Order Management – the system incorporates workflows that can be customised to track the progress of EOT requests, EOT approvals and change orders, as well as the consequent adjustments to project scope and costs
  • Risk Assessment and Mitigation – by analysing historical project data and key performance indicators (KPIs), the system can identify patterns, trends and potential risks associated with project delays. This information can then be used to inform risk mitigation strategies.

Leveraging insights from construction ERP software can help construction clients and contractors manage and minimise the impact of delays and deliver successful, profitable projects.

To find out more about RedSky’s award-winning Construction ERP software, visit our website or call one of our friendly team for a chat on +44 (0) 203 002 8600.